Lubbock Readiness Center Major Maintenance STAR Follow Solicitation

In accordance with the provisions of Texas Government Code (TGC) §437.054 and §2269 Subchapter D, Competitive Sealed Proposal Method, and Rules and Procedures, the Texas Military Department (TMD) Construction and Facilities Maintenance Office (CFMO) is soliciting proposals for Lubbock RC MM STAR located at 301 East Regis St., Lubbock Texas 79403.

The estimated construction budget for the services described in the Request for Proposal (RFP) is estimated Proposal Base is Twenty-Five Million Dollars (**$25,000,000.00**) with the estimated Proposal Options Six Million Two Hundred Thousand (**$6,200,000.00**).

The General Contractor shall provide all materials, equipment, labor, coordination, and supervisory activities necessary to complete construction of the project. This project is part of the STAR program and will renovate an approx. 129,000 SF Readiness Center. Work includes mitigation of current health, safety, and code deficiencies, as well as improving mission capabilities and force protection, as indicated in the Contract Documents except if delineated as a Proposal Option.

Interior building improvements include Structural, Architectural, Interiors, Fire Protection, Plumbing, Mechanical, Electrical, and IT/Telecom trades. Exterior building improvements include site Civil modifications for utilities, drainage, lighting, pavements, and fencing. Lead Protocol and Mold Remediation will also be required.

**Submission:** Competitive Sealed Proposals for TMD26-CFMO-0046268 will be received by the TMD until **10:00 AM CT, Tuesday, March 9, 2027**, at Camp Mabry, building 37, Austin, Texas 78703.

General Contractors must request via email FY27LubbockRCMM@cfmo.mil.texas.gov the Drawings/Plans and Specifications electronically in digital format.

**Mandatory site visits:** General Contractors MUST attend one (1) of the two (2) MANDATORY site visits. Failure to have an employee or authorized representative attend one of the two mandatory site visits on behalf of the prospective Respondent will result in disqualification of the Proposal. The site visits are public events; subcontractors are welcome to attend and network with prospective General Contractors.

**Contract term:** The TMD will issue a Notice to Proceed within 90 days of the contract award, stating the date(s) for beginning Work and achieving Substantial Completion of the Work. The Respondent will provide the performance period in calendar days in Attachment A, 2. Performance Period. The approximate project completion date is October 2028.

Payment must be made in accordance with Texas Government Code, Chapter 2251, commonly known as the Texas Prompt Payment Act.